Hi,
I have one question.
If I submit a programme from excel, with no link, update. Is that document recognise during arbritation or court ?
BR
Excel Programme
Forum Sponsor
Top Posters
Julian Pegg
1 posts
Peter Nagy
2 posts
Raymund de Laza
17 posts
Syed_Asad
0 posts
Tony Greyvenstein
0 posts
Ahmed Al-Jubouri
13 posts
Umar Alvi
3 posts
Sibusiso Mahlalela
0 posts
Michael Samanyayi
3 posts
Simon Gumede
0 posts
Hi Ch
Impacted as planned - not suitable for forensic analysis
Time Impact - compares the impacted plan with the as built programme
As built v As planned - compares the as planned with the as built - suitable for sub-contract situations
As Built but For (colapsed as built) - removes the delay element from the as built programme to colapse it back to the as planned.
Best regards
Mike Testro
Can I have advice what are the 4 methods ?
Hi CH
A fully detailed delay analysis using any one of the four recognised methods can quite often confuse the arbtrators.
It all depends on who is arbitrating - if the person is an acknowledged delay expert then he/she would expect to see a robust delay analysis and an excell sheet would not be enough.
Otherwise a simple narrative backed up with excell pictures could be enough to simply explain the problem to a non techncal judge.
Best regards
Mike Testro
Is a programme essential, a must?
Can I substantial all my claim with letters to the contractor only ?
My problem is that the way the company works, we never update the schedule, even we use P6 or MS project. We just submit a new programme to reflect and revise on our new schedule ... It show no actuals, no update, no changing of data date and thinsg are kept to very simple, just a hard copy for reference. Would this be useful for arbitratory?
Kindly advice
I am arbitrating an EOT claimed over an excel programme.
It does not provide enough proof to sustain the claim and makes me think that the contractor is incompetent and that all the delays were its responsibility for not having an ongoing CPM update process to manage the project.
I am serious.
Best regards,
Carlos.