Got any questions about Claim Assessment
Hi,
Does the Engineer have rights to reject the Program submitted by the contractor as per clause 14, If yes, on what conditions and reasons?
Cheers Tanveer
Hi Guys,
The Contract Duartion is 23 December 2009 - 30 April 2012. The Employer is using FIDIC 1999. When I joined them in February 2012, I start notifying the Engineers regarding the delay and disruption at site in monthly basis. Then, I send Interim EOT submission at early week of April 2012. The Engineers reply to me rejected because we did not do as per Sub Clause 20.1, he is correct, we did not notify him within 28 days when delay occurs. The event is NOC from third party authority, it occurs in Nov 2011. The event is stil continuing up to date.
Hi
Clause 14 FIDIC 1987 – “The contractor shall, within the time stated in Part II of these Conditions after the date of the Letter of Acceptance, submit to the Engineer for his consent a programme, in such detail as the Engineer shall reasonably prescribe, for the execution of the work. …..”
Clause 8.3 FIDIC 1999 (Red Book) – “The Contractor shall submit a detailed programme to the Engineer within 28 days after receiving the notice under Sub-Clause 8.1 [Commencement of Works]. ….”
Hi Analysts
Would any one tell me the difference between Time Impact Analysis and Delay Analysis
Cheers
Tanveer
Dear All,
I am prastya from indonesia
If the owner request to acceleration for one building (BSDG) of CFSPP project (not incritical path) but the other building incritical path still on going and the building have already delayed from schedule. Some manpower and equipment from jobs at critical path used to the BSDG acceleration. as this matter my company proposed claim to owner regarding acceleration, what the best explanation to owner for this claim?
I highly appreciate yours prompt reply
Regards,
prastya
I am referring to the Mike part of reply to my previous post
"..........This is based on the principle that if there is no BOQ item to price then the obligation is not included in the contract price....." .
I have case where certain items are not priced in B.o.Q but are covered in specification.As per the condition of sub contract ,specification take precedence to other documents.
Am I justified in arguing that what is not priced in B.o.Q i
Within Claims there is a balance between liability and quantum, has anyone had an experience in producing or working with a claims document that presents accountability of liability and cost, in an optmal setting to give the demonstrator of burden of proof enough information to settle the claim; before going any further into the arbitration process.
When is OpenOffice going to develop or provide a project management tool similar too Microsoft Project?
Or is that not a viable solution in the future?
Dear All,
Would like to know ,how the obligations differs between "Defect Liability Period" and "Maintenance Period".
Our contract agreement calls for 3 years DLP, whereas B.O.Q includes".......maintenance for the guarantee period".
Can these be considered same ..as our client expecting us carry out all works ,usually used to be part of Annual Maintenance contract.
As per our contract in case of discrepancy contract agreement take precedence over the pricing documents.
What shall
Hi all analysts,
I need your expert comments on;
