It comes down to what your EoT clauses say and why you are claiming:
For example, an EoT clause which says the contractor is entitled to "likely or future delays" will need some form of prospective (normally dynamic) analysis to determine when that contractual right accrued. One that says "has caused delay" will possibly lend itself to a retrospective method (generally static) but a dynamic method could still be used, it would just need careful consideration as to when in the analysis the right to an EoT acrued.
But, say your claim is for late information and the employers obligation is to supply it "with regards to the progress of the works". The method of analysis would have to take this into account and therefore a dynamic one probably be more suited.
But, as Toby said, everything in proportion to the value of the claim. Dynamic methods tend to take along time to do and are hence more expensive than a static method.
Static methods though are usually quite easy to tear apart and dispute, dynamic methods more are difficult as they demonstrate cause and effect much more clearly.
Member for
18 years 9 months
Member for18 years10 months
Submitted by Allan Barclay on Thu, 2007-07-26 16:37
I didnt state that the person making the submission should decide on the method. You have to submit the best case you can at all times. I was stating that i have generally had a better success rate on claims, if you tailor your submission/ presentation to suit the person who is reviewing the claim - be it and adjudicator/ arbitrator client whatever. I agree that the value and timescale are important in relation to any submission, as is the amount of information and expertise available.
If you want some bedtime reading and a very thorough read on the subject, try Keith Pickavances "Delay & Disruption in Construction Contracts", now in its 3rd edition.
Generally, static methods of analysis are relatively quick, simple and cheap to perform, but if the planned activities vary in duration or sequence during the course of the project these methods of analysis will not produce as accurate a result as a dynamic method such as time impact analysis, which takes changes in the baseline into account.
I dont think you should rely on the person doing your claim submission to decide the method for you; the choice of method should depend on your timescale and budget (which should be proportional as to the amount in dispute) as well as what information available to you.
Member for
18 years 9 months
Member for18 years10 months
Submitted by Allan Barclay on Wed, 2007-07-25 19:43
I believe that the key is the requirements of the Contract. Some Contracts require frequent monitoring / statusing of the Contract Programme. This programme can not be static then, can it?
I failed to attach the link to Daniels paper, if you know his web site, go the the "Role of the Programme of Works"
article and then look for the dynamic role of the programme
Member for
18 years 9 months
Member for18 years10 months
Submitted by Allan Barclay on Wed, 2007-07-25 19:23
its an inhouse company session, we have started giving in house talks on areas of our own expertise as a training mechanism for our younger staff.
I was just interested in some feed back on what people thought of the differences and their own preferences, because as you say different people have different approaches.
the key i suupose is to know the approach of the person assessing your claim submission and tailor it to suit them.
Sorry, yes i meant in relation to the contract programme.
I am going to a seminar next week at which my collegue is going to discuss the merits/ differences of static and dynamic analysis of programmes in relation to delays etc.
can u elaborate? r u refering to the Contract Program? In that case i am defintely for the dynamic!
there is an excellent web site by a Brit solicitor, Daniel Atkinson. Youll find there an article, i think it is called "the dynamic role of the program" or something. If u can not find it let me know, and Ill soirce it for you.
Member for
19 years 10 monthsHi LiaqatA static delay
Hi Liaqat
A static delay analysis is where nothing is linked up - impacted or moved.
The classic example being As Built v As Planned.
Best regards
Mike Testro
Member for
15 years 10 monthscan somebody explain static
can somebody explain static method with a simple case study or example .I actually need one such example
Member for
19 years 1 monthRE: Static v Dynamic Analysis
for me, you dont need to select because youll always need both for comparison
my understanding (very little) is that Static Analysis applies to your Baseline / Target Program, while Dynamic Analysis applies to all
Member for
20 years 10 monthsRE: Static v Dynamic Analysis
Both Uri and Toby have valid points.
It comes down to what your EoT clauses say and why you are claiming:
For example, an EoT clause which says the contractor is entitled to "likely or future delays" will need some form of prospective (normally dynamic) analysis to determine when that contractual right accrued. One that says "has caused delay" will possibly lend itself to a retrospective method (generally static) but a dynamic method could still be used, it would just need careful consideration as to when in the analysis the right to an EoT acrued.
But, say your claim is for late information and the employers obligation is to supply it "with regards to the progress of the works". The method of analysis would have to take this into account and therefore a dynamic one probably be more suited.
But, as Toby said, everything in proportion to the value of the claim. Dynamic methods tend to take along time to do and are hence more expensive than a static method.
Static methods though are usually quite easy to tear apart and dispute, dynamic methods more are difficult as they demonstrate cause and effect much more clearly.
Member for
18 years 9 monthsRE: Static v Dynamic Analysis
Thanks for that.
I didnt state that the person making the submission should decide on the method. You have to submit the best case you can at all times. I was stating that i have generally had a better success rate on claims, if you tailor your submission/ presentation to suit the person who is reviewing the claim - be it and adjudicator/ arbitrator client whatever. I agree that the value and timescale are important in relation to any submission, as is the amount of information and expertise available.
Member for
18 years 3 monthsRE: Static v Dynamic Analysis
Allan,
If you want some bedtime reading and a very thorough read on the subject, try Keith Pickavances "Delay & Disruption in Construction Contracts", now in its 3rd edition.
Generally, static methods of analysis are relatively quick, simple and cheap to perform, but if the planned activities vary in duration or sequence during the course of the project these methods of analysis will not produce as accurate a result as a dynamic method such as time impact analysis, which takes changes in the baseline into account.
I dont think you should rely on the person doing your claim submission to decide the method for you; the choice of method should depend on your timescale and budget (which should be proportional as to the amount in dispute) as well as what information available to you.
Member for
18 years 9 monthsRE: Static v Dynamic Analysis
I have read that articel, i was hoping there was something more.
if you have any additional articles on the subject i would be interested.
thanks
Member for
22 years 5 monthsRE: Static v Dynamic Analysis
Allan,
I believe that the key is the requirements of the Contract. Some Contracts require frequent monitoring / statusing of the Contract Programme. This programme can not be static then, can it?
I failed to attach the link to Daniels paper, if you know his web site, go the the "Role of the Programme of Works"
article and then look for the dynamic role of the programme
Member for
18 years 9 monthsRE: Static v Dynamic Analysis
its an inhouse company session, we have started giving in house talks on areas of our own expertise as a training mechanism for our younger staff.
I was just interested in some feed back on what people thought of the differences and their own preferences, because as you say different people have different approaches.
the key i suupose is to know the approach of the person assessing your claim submission and tailor it to suit them.
Member for
22 years 5 monthsRE: Static v Dynamic Analysis
Allan,
Youll find that there are two main schools of thought in Delay Analysis: the old school, and the modern way of thinking.
the old school will probably support the static aproach whereas the modern - dynamic approach.
where is this seminar taking place? who is running it?
Im interested because we run EOT seminars for Project managers and CAs in Sydney.
Member for
18 years 9 monthsRE: Static v Dynamic Analysis
I have used Daniels site quite a bit, but havent found that article. if you can find it then that would be great.
Member for
18 years 9 monthsRE: Static v Dynamic Analysis
Sorry, yes i meant in relation to the contract programme.
I am going to a seminar next week at which my collegue is going to discuss the merits/ differences of static and dynamic analysis of programmes in relation to delays etc.
Member for
22 years 5 monthsRE: Static v Dynamic Analysis
Allan,
can u elaborate? r u refering to the Contract Program? In that case i am defintely for the dynamic!
there is an excellent web site by a Brit solicitor, Daniel Atkinson. Youll find there an article, i think it is called "the dynamic role of the program" or something. If u can not find it let me know, and Ill soirce it for you.