How about best practice for documenting delays in the schedule as activities and or notbook entries. Is there are accepted best practace / documents on this.
It is noteworthy that the need for analysts to take resource allocations into account in their delay analyses is becoming an increasingly vital requirement. For instance, in the UK case of McAlpine Humberoak vrs McDermott International [29], the judge disapproved of the plaintiff’s delay claim submissions on the basis of not giving consideration on how resource usage was planned for and how they were actually utilized during construction. Wickwire [43] also reviewed legal decisions in the US and noted that “in any analysis of project delays, the contractor is required to take into account realistic resource leveling”.
Spider Project is most functional and powerful professional project management software.
The first SP version was launched in 1993 and since then it has been constantly improved. Today is used in 34 countries though most Spider Project customers are in Russia. Spider Project offers numerous unique functional features and is the only PM software that optimizes resource, cost, and material constrained schedules and budgets for projects and portfolios.
The unique features of Spider Project include Quantity Based Scheduling, Conditional Scheduling, Skill Scheduling, Optimal Resource, Cost and Material Leveling, Resource Critical Path Calculation, Cash and Material Flows Calculation and Management, Trend Analysis, Advanced Risk Simulation and Analysis, Calculation of Success Probability Trends, Calculation and Management of required Project Time and Cost Buffers, Application of Corporate Norms, Management of many Parallel Budgets, Multiple WBS and many others.
Spider Project was and is used for management of many large scale programs in Russia, including $51bln construction program for 2014 Winter Olympic Games preparation.
The application areas where Spider Project is successfully used include Aerospace, Banking, Construction, Defense, Energy, Engineering, Infrastructure, Manufacturing, Metallurgy, Mining, Oil & Gas, Railways, Retail, Shipbuilding, Software Development, Telecommunications, Utilities, etc.
P6-Auditor - Display information from Primavera P6 audit tables in a user-friendly format
Unifier-Archiver - Extract and archive important documents and attachments from Primavera Unifier
Unifier-Loader - Load data into and out of Unifier via Excel
PCM-Loader - Import data into Primavera Contract Management with flexible and secure, template-driven Excel spreadsheets
PCM-Archiver - Extract and archive important documents and attachments from Primavera Contract Management
PCM-Unifier Migrator - Automatically transfer live and historical data from Primavera Contract Management to Primavera Unifier with ease
Create Radically Better Construction Schedules with ALICE Technologies
Use the power of AI to create construction schedules that reduce risk while cutting costs and build time. With ALICE, develop the ideal schedule during preconstruction -- or recover projects that are off schedule and over budget.
How about best practice for documenting delays in the schedule as activities and or notbook entries. Is there are accepted best practace / documents on this.
How about the documentation of the delay in the schedule as it occurs - delay activities. Is there a recomended practice for this?
look at this presentation
https://www.linkedin.com/posts/%D8%B9%D9%84%D9%85-%D9%8A%D9%86%D8%AA%D9…
look at AACE Best Practice No 29R-02 Forenesic Analsis
and
AACE Best Practice Time Impact Analysis 52R-06
Construction Delay Analysis Techniques—A Review of Application Issues and Improvement Needs
It is noteworthy that the need for analysts to take resource allocations into account in their delay analyses is becoming an increasingly vital requirement. For instance, in the UK case of McAlpine Humberoak vrs McDermott International [29], the judge disapproved of the plaintiff’s delay claim submissions on the basis of not giving consideration on how resource usage was planned for and how they were actually utilized during construction. Wickwire [43] also reviewed legal decisions in the US and noted that “in any analysis of project delays, the contractor is required to take into account realistic resource leveling”.
Schedule Analysis under the Effect of Resource Allocation (PDF)
Schedule Float Game ENR