Website Upgrade Incoming - we're working on a new look (and speed!) standby while we deliver the project

Tips on using this forum..

(1) Explain your problem, don't simply post "This isn't working". What were you doing when you faced the problem? What have you tried to resolve - did you look for a solution using "Search" ? Has it happened just once or several times?

(2) It's also good to get feedback when a solution is found, return to the original post to explain how it was resolved so that more people can also use the results.

The Society of Construction Law (Australia)

25 replies [Last post]
David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
The Society of Construction Law (UK) is promoting the establishment of the SCL in Australia.

Since its foundation in 1983, the Society of Construction Law (UK) has worked to promote for the public benefit education, study and research in the field of construction law and related subjects (including adr, arbitration and adjudication), both in the UK and overseas.

Those who are interested and professionally involved in construction law should contact Keith Kirkwood who is co-ordinating initial interest.

keith.kirkwood@drivergroupplc.com

Replies

Anders Axelson
User offline. Last seen 3 years 45 weeks ago. Offline
Joined: 6 Dec 2003
Posts: 41
Groups: None
Dear all,

I can advise that this organization (The Society of Construction Law Australia) is now up and running!

For those Planning Planet members who may be interested in joining, I understand that an interactive online application form should be available on the website within the next few weeks at href=’http://www.scl.org.au’>www.scl.org.au.

Alternatively, please feel free to email me via this forum if you require an application form before then.

Regards

Anders Axelson
href=’http://www.pezala.com’>Pezala Consulting
Trevor Rabey
User offline. Last seen 2 years 1 week ago. Offline
Joined: 29 Nov 2005
Posts: 530
Groups: None
Trevor Rabey
User offline. Last seen 2 years 1 week ago. Offline
Joined: 29 Nov 2005
Posts: 530
Groups: None
Trevor Rabey
User offline. Last seen 2 years 1 week ago. Offline
Joined: 29 Nov 2005
Posts: 530
Groups: None
Trevor Rabey
User offline. Last seen 2 years 1 week ago. Offline
Joined: 29 Nov 2005
Posts: 530
Groups: None
Anders Axelson
User offline. Last seen 3 years 45 weeks ago. Offline
Joined: 6 Dec 2003
Posts: 41
Groups: None
David,

Yeah, I know - I’m a member of both organisations, and know them both well. I know them to be very similar, if not identical, in their objectives. I was making the point because I was bemused that each seemed to be labouring under misconceptions about the other.

I’m well aware of your research into delay and disruption. In fact, a paper that you wrote in the 1990s that I recall appeared in the journal "Construction Management & Economics" was one of my first ever introductions to the subject!!

Regards

Anders.
David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
Anders

Sorry if I gave the wrong impression - I am sure I didn’t say they didn’t want to be associated with a ’disputes’ society. I though I said I felt they might not like to be compared to a ’disputes’ society because they are about the whole spectrum of construction law. I am not a spokesmen for the SCL (in this instance I started the thread on behalf of my colleague Keith Kirkwood).

Also, not sure about what you mean by BDPS and the SCL. The SCL is an inclusive society... to become a member all you have to do is have an interest in construction law. I am not a lawyer by any stretch of the imagination - but because I work for a consultant (and , sorry, most of my business is in claims and disputes) I have to try to keep up to day with developments and changes; case law. legislation, techniques, discussions and so on.

I really did not mean to start any sort of agravation or assault on anyone (well, except for Charlie that is). 15 years ago-ish when I was researching delay and disruption there was an awful lots of advanced stuff (more than I could find from UK at that time) so as a previous poster said there is not a lot we Brits can teach the Aussies but that isn’t, from what I understand, the intent of the the SCL - and again, I thought I made that clear in my first post.

Regards

David
Anders Axelson
User offline. Last seen 3 years 45 weeks ago. Offline
Joined: 6 Dec 2003
Posts: 41
Groups: None
David,

Interesting that you should mention that might be an objection for the SCL to associate with a "disputes" society...

In the past, I understand that the Building Disputes Practitioners Society has equally taken a high moral ground about associating with the Society of Construction "Law" - on the basis that it is intended to be an inclusive organisation for practitioners across the industry - not just lawyers!!

Regards

Anders.
Cherie S Blare
User offline. Last seen 15 years 43 weeks ago. Offline
Joined: 7 Jan 2006
Posts: 41
Groups: None
Desert boy needs to go back to grammar school....
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
AS A LAST SHOUT

YOUR FIRST THREAD IS AN INSULT TO THE

AUSTRALIAN
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
for the benifit of english speaking.

ADIOS is the spanish word for


GOODBYE
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
walang salamat sa iyo !!!

in english

no thanks to you
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
you started it

so now you backpedalled.

anyway there is nothing in your first thread.

ADIOS

Walang salamat sa iyo.

David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
Charlie...
Whilst I agree, what you say happens: "Beside, if you stay in this planet for too long, you will know that idea jump from the original intent of the thread to other idea, then to other idea, then go back to the original intent, and so on and so forth."
But, that like amany of the things you espouse, is not good practice. Keeping to the matter in hand an concentrating on the subject is the best way to get it resolved. By all means start another thread on a related subject but don’t hijack other threads to spout nonsense.
If you want to talk nonsense then start athread of you own, that way serious contributors an decide whether to join you on planet weirdo or not.
D
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
david said "he is only a messenger"

perhaps, David can make rebuttal on some issue but I like to handle it like in a lively debate for example

"RESOLVE THAT EOT PROTOCOL FROM SCL SHOULD NOT BE ENTERTAINED BY PROJECT MANAGEMENT PRACTITIONER."

There will be pros and cons

I’m also interested to highlights some best idea from AACEI.

of course on our free time since I’m involved in a big job
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
Toby,

I know what David intent in his first post.

But, as he said, "I tempted fate"

So, David is practically making an opening gambit, baiting me.

Also, I want to quetion SCL on the way they handle the eot protocol here in PP

Beside, if you stay in this planet for too long, you will know that idea jump from the original intent of the thread to other idea, then to other idea, then go back to the original intent, and so on and so forth.

Toby Hunt
User offline. Last seen 11 years 6 weeks ago. Offline
Joined: 26 Jul 2007
Posts: 98
Groups: None
Charlie, that post was hilarious.

I agree with David, and think that you may have missed the point of this thread.

In the future I would suggest that you remove the gun from the holster before firing, or you may end up shooting yourself in the foot.
David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
It’s all my fault - I tempted fate!

Sometimes Charlie gets the wrong end of the stick... this time he has picked up the wrong stick. Oh Lord, help us!
Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
and during revision as per clause 14,

the contractor was pressuring us to approve the revise baseline program otherwise they will unilaterally declare "TIME AT LARGE"

Again such term from EOT protocal by SCL

I did not recommend to approve the revise baseline program because it projected the completion date beyond the contractual completion date. At the time the revise baseline was submitted, the project was two years after the start of project in a four years contractual project duration, so fifty percent actual project duration.

Beside, the baseline program contains a lot of constraints, a lot of open ended activities to the point that there was distortion of logic, you really can not understand the CPM or the longest path. Even the contractor can not understand there own schedule

BUT, just the same I did hear the scream "APPROVE OR TIME AT LARGE"

Again, EOT protocol used in a devious way, can really intimidate lesser individuals. My colleagues approve, but I made it clear, I dont agree. so my time in the project is numbered because I did not back down.

Charleston-Joseph...
User offline. Last seen 3 years 18 weeks ago. Offline
Joined: 10 Jul 2005
Posts: 1347
Groups: None
Hello David,

I did think for a while on how to respond to SCL in general and the EOT protocal by SCL in particular.

WOW, I love this.

Basically I got this funny experience woring in a project team as project control engineer wherein the first email i got on my first day is the EOT protocol from SCL. I really wonder how it comes to our office. I’m working in the project management.

As my stay in that project (I resigned long time ago) move with time, I got a feeling that the contractor is deliberately programming activities to start too early with too much float and deliberately delaying the starts of activitiies with matching letters "... we reserve our rights to claim for extension of time with corresponding prolongation cost blah blah blah and blah, etc...."

To make the story short, IMHO, the EOT protocol from SCL is the antichrist (666)to sound project management principles.

Why this is so???????

SCL don’t want to make mockery of the EOT protocol, but there is no way, that protocal will improve unless it is bombarded with tough question from project management practioner.

In fairness, anyone within the project management higher management thinking in line with EOT protocal from SCL will definitely fail the project.

David, do you want to rock and roll. This time we will focus on specific issues within the EOT protocol and compare it with other practice from the English’s cousin, the Americans, specifically, AACEI.

Charlie
David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
Anders...
Just a quick one...
You are right about Australia not being a branch of Uk - I hope I did not geive that impression.
Aslo, I think the SCL would be dissapointed to be compared to a body with ’Disputes’ as its raison d’etre. Much of what the SCL do is outside the disputes area and even the much maligned (in some quarters) Delay and Disruption Protocol is as much about good practice and avoiding disputes as how to go about solving them.
Regards
David

Hmmmmm... wonder why Charlie hasn’t come into this thread yet, he usually has some pearls of wisdom to add!
Anders Axelson
User offline. Last seen 3 years 45 weeks ago. Offline
Joined: 6 Dec 2003
Posts: 41
Groups: None
Dear all,

Unless I am hugely mistaken, the UK SCL is not simply seeking to set up an Australian branch of the UK SCL – it is encouraging a stand-alone, independent Australian society in the same way that SCLs in other jurisdictions (e.g. UAE, Hong Kong, New Zealand, Malaysia, Singapore etc.) have been established. As it happens, however, there is already established in Australia the Building Dispute Practitioners’ Society, which is based in Melbourne (see www.bdps.com.au). The BDPS, I understand, is long-established (it pre-dates the UK SCL) and well supported, with close ties to the Bar, major firms, judiciary, academia, etc., serving basically an identical function to that of the SCL in the UK. But it is only really in Victoria at present – although I do understand it may be considering setting up elsewhere, using its members’ plentiful ties with dispute practitioners in other states as a springboard for doing so.

Not that I purport to speak for either the SCL or the BDPS!)

Regards

Anders.
Toby Hunt
User offline. Last seen 11 years 6 weeks ago. Offline
Joined: 26 Jul 2007
Posts: 98
Groups: None
Trevor

Don’t worry, you won’t get too many UK people trying to tell you guys what to do!

The SCL has been a success in the UK, and if this can be repeated in Australia then you should encourage it. It is a good forum for learning.

Regards

Toby
David Bordoli
User offline. Last seen 8 years 31 weeks ago. Offline
Joined: 8 Apr 2002
Posts: 416
Hi Trevor...

I am only the messenger!

But if you look at the brief aims of the SCL I noted in my posting you will see it is a learned society for those interested in all aspects of construction law. So, as far as I know it is not replacing anything.

I guess the reason why the SCL is promoting the establishment of an Australian SCL is that being alturistic and philantropic they think the Antipodean construction industry and its members/ supporter/ judiciary etc might benefit.

David
Trevor Rabey
User offline. Last seen 2 years 1 week ago. Offline
Joined: 29 Nov 2005
Posts: 530
Groups: None
David, why is The Society of Construction Law (UK)promoting the establishment of the SCL in Australia?

Is there any need being met?
What does it replace and why is it better?

Australia already has all of the ingredients, a legal system, and a firmly established tradition of pear shaped projects followed traditionally by construction disputes with all of the accoutrements of arbitration, legislation and litigation, barristers and experts.